Effective Date: 12/4/2024
Welcome to Assured Builders. By using our website or services, you agree to comply with and be bound by the following Terms and Conditions. If you do not agree with these terms, please refrain from using our website or services.
1. Definitions
- “Company” refers to Assured Builders.
- “User” refers to any individual accessing or using our website or services.
- “Services” refer to the construction, renovation, and related offerings provided by Assured Builders.
2. Use of the Website
- The content on this website is for general information purposes only and is subject to change without notice.
- You are responsible for ensuring that any information you provide is accurate and up-to-date.
- Unauthorized use of this website may give rise to a claim for damages and/or be a criminal offense.
3. Services and Agreements
- All service agreements are subject to approval and availability.
- Detailed terms for specific projects, including timelines, costs, and warranties, will be outlined in individual contracts.
- The company reserves the right to refuse or terminate services if deemed necessary.
4. Intellectual Property
- All content, including text, graphics, and images, is the property of Assured Builders and is protected by copyright and intellectual property laws.
- Reproduction, distribution, or use of our content without written permission is prohibited.
5. Payment Terms
- Payment schedules and amounts will be agreed upon in your individual project contract.
- Late payments may incur penalties as outlined in the contract.
- All payments must be made in accordance with the agreed terms to avoid delays or suspension of work.
6. Liability
- Assured Builders is not liable for indirect, incidental, or consequential damages arising from the use of our services or website.
- While we strive for accuracy, we do not guarantee that our website content is error-free or up-to-date.
- The company is not responsible for delays or issues caused by external factors beyond our control, such as weather conditions or material shortages.
7. Privacy
Your use of our website is governed by our Privacy Policy. By using our services, you consent to the collection and use of your information as described therein.
8. Cancellation Policy
- Cancellations must be made in writing and may be subject to fees as outlined in your contract.
- Refunds, if applicable, will be processed in accordance with the terms of the individual service agreement.
9. Third-Party Links
Our website may contain links to external websites. We are not responsible for the content, privacy practices, or availability of these third-party sites.
10. Governing Law
These Terms and Conditions are governed by the laws of Manitoba, Canada. Any disputes arising from your use of our website or services will be subject to the jurisdiction of the courts of Manitoba.
11. Changes to Terms
Assured Builders reserves the right to update or modify these Terms and Conditions at any time without prior notice. Changes will be posted on this page with the revised effective date.
12. Contact Us
For questions or concerns about these Terms and Conditions, please contact us:
Assured Builders
115 Strand Circle
Winnipeg, Manitoba
Phone: 204-998-1850
Email: reply@assuredpropertymgmt.com
By using our website and services, you acknowledge that you have read, understood, and agreed to these Terms and Conditions. Thank you for choosing Assured Builders!